CASE OVERVIEW
We filed the case before Real Estate Courts in Dubai requesting 1. Cancelation of the purchase agreements for failure to handover the villas on the date agreed in the agreements, 2. Refund of the paid amount (AED7,400,000), and 3. 9% interest.
PARTIES’ ARGUMENTS
Developer Arguments
The developer presented several arguments challenging the jurisdiction of the Dubai Real Estate Court and the nature of the project’s delays. These arguments were crucial in determining the legal status of such floating villas under the UAE law.
- Jurisdictional Challenge/Classification of the Villas: The developer contended that the floating villas, being akin to ships, do not fall under the provisions of the Dubai Real Estate Court. They argued that such floating structures should be tried under maritime law, not real estate law.
- Innovative/Uniqueness Nature of the Project: The project’s unique/innovative nature as the first of its kind in the UAE and Middle East led to delays in obtaining the Objection Certificate (NOC) from the main developer.
- Force Majeure: The developer attributed the delays in completing the project to various factors they considered beyond their control, invoking the Force Majeure clause in the Purchase Agreements.
- Delays in Obtaining Licenses from Government Authorities: There were additional delays in securing necessary licenses from government bodies stating as a reason the project’s uniqueness/innovative nature in the UAE and the Middle East.
- Weather-Related Disruptions: Being an island-based project, weather variations halted work frequently. Transportation challenges for labor and materials due to weather were presented as uncontrollable natural events, fitting the ‘Force Majeure’ clause in the Purchase Agreements.
- Project Registration Status: The project’s non-registration with the Dubai Land Department (DLD) was justified on the basis that floating villas are considered ships, not real estate, therefore exempting them from standard real estate property registration requirements.
Buyer’s Arguments/Our Counter Arguments
- Jurisdictional Challenge/Classification of the Villas: At the outset, we had to challenge the argument that floating villas are ships or boats. It was important that we had to delve into the UAE Maritim Law to confirm the specific characteristics that distinguish these types of structures and how they align with legal definitions and practical functionality, as follows:
Definition/Specifications of a ‘Ship’ under the UAE Maritime Law
Key Feature of a Ship: A fundamental aspect of a ship or boat, as understood in the UAE Maritime Law, is its inherent capability to navigate waterways. This typically involves the ability to be steered and propelled through water, either by mechanical means (like engines) or by natural forces (like sails).
Lack of Navigation Ability: Floating villas, in contrast, lack these navigational capabilities. They are not designed or equipped to sail or move independently on water. Their primary function is stationary habitation, not transportation or navigation.
Construction and Design: The design and construction of floating villas are more akin to stationary structures on land rather than sea-faring vessels. They are typically anchored or tethered to a specific location and do not have the structural features necessary for safe and effective navigation (such as a hull designed to handle varying sea conditions).
Purpose and Usage: The primary purpose of floating villas is residential living, similar to a house on land. This is fundamentally different from ships or boats, whose primary purposes range from transportation and recreation to commercial activities.
Legal and Regulatory Compliance: Ships are subject to a different set of regulatory standards and inspections, focusing on navigational safety, seaworthiness, and maritime conduct. Floating villas as they have been marketed and sold as are classified as stationary residential units and as such do not meet maritime standards, nor are they were intended to at the time of the sale.
Property Laws: The classification of floating villas as real estate properties rather than ships aligns them with land-based property laws, encompassing aspects like real estate registration, property rights, and relevant local building codes.
Precedents and Comparative Analysis: In various international jurisdictions, there have been similar debates about the classification of floating structures. Often, the determination hinges on the ability to navigate and the primary purpose of the structure.
In summary, the argument that floating villas are not ships or boats rests on their lack of navigational capabilities, their design and purpose for stationary living, and the regulatory and legal frameworks that more appropriately categorize them as real estate rather than maritime vessels.
This understanding and classification are crucial in applying the correct legal principles and regulations to such structures and take the dispute forward to be addressed and judged in accordance with the Laws and Regulations intended for Real Estate Developments.
Therefore, under UAE Real Estate Laws, these structures should be recognized as real estate properties, not maritime vessels.
2. Developer’s Responsibilities for Obtaining Approvals and Licenses from Relevant Government Authorities.
We underscored the fundamental obligation of the developer to obtain a comprehensive range of approvals and licenses prior to initiating the project or marketing any units according to Real Estate Laws.
This critical preparatory phase encompasses several key steps:
Obtaining No Objection Certificates (NOC)
Purpose: NOCs are official documents issued by relevant authorities indicating approval for specific aspects of a project. They serve as a green light for various stages of development.
Local Authorities Involved: Depending on the project’s nature and location, NOCs are required from local planning departments, environmental agencies, utility providers, and other relevant governmental bodies. Each NOC addresses different aspects, such as environmental impact, structural safety, and compliance with urban planning guidelines.
Securing Relevant Licenses & Approvals
Types of Licenses: These may include construction licenses, operational permits, and other regulatory approvals specific to the nature of the project.
Regulatory Compliance: These licenses ensure that the project adheres to local and national building codes, safety standards, and other regulatory requirements.
Adherence to Government Regulations
Compliance with Laws: Developers must comply with a range of laws, including those related to real estate, environmental protection, labor, and commercial activities.
Impact on Project Timeline: Failure to adhere to these regulations can lead to significant delays, legal complications, and additional costs.
In conclusion, our argument highlighted the comprehensive nature of these prerequisites, emphasizing that the developer’s failure to secure these approvals and licenses in a timely manner was a significant oversight, impacting the project’s progress and leading to the delays encountered.
This responsibility is not only a legal requirement, but also a matter of ethical business practice in the real estate industry.
3. Weather-Related Delays/Force Majeur
While the developer blamed weather fluctuations for the project’s delays, hence, developer has relied on Force Majeur, we argued that such weather conditions were foreseeable. A competent developer should anticipate and plan for such challenges, especially in projects located on islands.
Addressing Weather-Related Delays in Innovative Project Locations: We confronted their claim that weather fluctuations at the island-based project site were unexpected, leading to delays. Our stance was firmly rooted in the principle of thorough preparation and foresight, especially in pioneering real estate ventures.
4. Expectation of Due Diligence in Uncharted Locations
Developer’s Responsibility: When embarking on projects in unique or previously undeveloped locations, such as island sites, it is incumbent upon the developer to conduct extensive research and environmental studies. This includes understanding the local climate, seasonal weather patterns, and potential natural disruptions. Such locations often present distinct challenges, ranging from logistical complexities to environmental unpredictability.
5. Proactive Planning and Risk Mitigation
Given the project’s island location, weather-related challenges should have been anticipated. This includes planning for transportation difficulties, supply chain disruptions, and construction delays due to adverse weather conditions.
Risk Management Strategies: A competent developer should incorporate risk management strategies into their project timeline and budget, accounting for potential delays and finding ways to mitigate these risks.
Meeting Deadlines: Developers must plan their projects in a way that aligns with the project completion deadlines as per the SPA.
Transparency with Buyers: It’s crucial to maintain transparent communication with buyers, especially when projects involve novel or challenging environments, to set realistic expectations about potential delays and how they will be addressed.
Our stance firmly attributed the project delays to the developer’s planning oversights and mismanagement, challenging their claim of ‘Force Majeure’. We emphasized that the inherent challenges of the unique project site, particularly weather-related issues, were foreseeable and should have been accounted for. Thus, we argued that their lack of preparation invalidated the invocation of the Force Majeure clause in the SPA.
COURT RULING
The Dubai Courts’ ruling in the floating villas case represents a crucial legal precedent, affirming that real estate developers cannot evade their obligations to clients by altering the classification of their projects. This decision not only brought justice in this particular case, but also set a clear standard for future real estate developments in the UAE.
Ruling Overview: The series of judgments by the Dubai Courts culminated in a definitive and enforceable ruling against the developer.
Dubai Court of First Instance Ruling
The Court of First Instance ruled in favor of our client, ordering 1. the termination of the Sales and Purchase Agreement (SPA); 2. the developer to refund the amount of AED 7,400,000, along with 5% interest from the date of filing the case until the complete payment is made, 3. all litigation costs and fees shall be borne by the developer.
Dubai Court of Appeal Ruling
The Court of Appeal upheld the original decision of the Court of First Instance, reaffirming the judgment in favor of our client.
Dubai Court of Cassation Ruling
The Court of Cassation affirmed the judgment passed by the Court of Appeal.
CONCLUSION
Broader Implications: The recent landmark ruling by the Dubai Courts marks a pivotal advancement in UAE real estate law, strengthening the legal framework by ensuring developers cannot bypass their obligations through project classification manipulations. Emphasizing the necessity for developers to rigorously adhere to all legal requirements, including obtaining necessary permissions and conducting thorough risk assessments for innovative projects, this decision enhances the integrity and reliability of the UAE’s real estate market. By preventing classification manipulation and reinforcing developer accountability, especially in complex projects, the ruling not only delivers justice in the present case but also establishes a robust framework for future real estate developments.
Impact on Developer’s Accountability:
- Setting a Legal Precedent: This case serves as a warning to developers engaging in innovative real estate projects. It establishes that attempting to shift jurisdiction or redefine project concepts post-development to evade responsibilities is not legally permissible.
- Protection for real estate investors: The ruling enhances the protection afforded to clients in real estate transactions, ensuring that developers adhere to the initial terms and classifications outlined in their agreements.
- Upholding Professional Responsibility: It reinforces the expectation of professional integrity and responsibility that developers must maintain throughout the lifecycle of their projects, from conception to completion.
ABOUT MOTEI & ASSOCIATES
We advise on the full spectrum of the real estate transactions involving sale and purchase of property, off plan projects, mortgaging, transfer of ownership, and landlord and tenant relationships. Our real estate litigators have handled a wide variety of disputes involving sale and purchase agreements, delayed handover, cancelled projects, and discrepancies in saleable area and rental disputes. For more info about our Real Estate Practice, please visit: https://motei.com/real-estate/.
For more information about this case, or should you wish to consult on a current real estate issue you are facing, please contact us at: contact@motei.com.
